Simple technical service contract model 1
Client (hereinafter referred to as Party A): _ _ _ _ _ _ _
Legal representative or person in charge: _ _ _ _ _ _ _
Service Party (hereinafter referred to as Party B): _ _ _ _ _ _ _
Legal representative or person in charge: _ _ _ _ _ _ _
This contract is signed by both parties through consultation.
Article 1 Project Name: _ _ _ _ _ _ _
(Note: This reference format can be applied to product design, process preparation, test analysis, computer programming, engineering calculation and other auxiliary technical service activities).
Article 2 Main obligations of Party A
1. Provide Party B with the following technical data, data, materials and samples within _ _ _ _ days after the contract comes into effect: _ _ _ _ _.
2. After receiving the notice from Party B about improving or replacing the technical data, materials and samples that are not in conformity with the contract, it shall make a timely reply within _ _ _ days;
3. Pay Party B _ _ _ _ _ yuan as agreed, and the payment method is as follows:
Pay _ _ _% of the total remuneration to Party B within _ _ days after the Contract comes into effect; Pay the balance of all remuneration to Party B within days after the completion of the contract (from the date of acceptance). (Note: Both parties may agree that Party B shall be responsible for reimbursement or one-time use, etc. )
Party B's bank account is _ _ _ _.
4. Assist Party B to complete the following cooperation matters: _ _ _ _ _ _.
Article 3 Main obligations of Party B
Complete technical service before 1._ _ _ _ _;
2. Complete technical services according to the following technical and economic indicators.
3. If it is found that the technical data, data, samples, materials or working conditions provided by Party A are inconsistent with the contract, it shall notify the entrusting party to improve or replace them within _ _ days after the contract comes into effect;
4. Keep the technical data and samples handed over by Party A properly; During the performance of the contract, if it is found that the continued work is in danger of damaging materials, samples or equipment, the work shall be suspended and the entrusting party shall be informed in time; After the work is completed, the above technical data and samples shall be returned, and copies shall not be kept without authorization.
Article 4 confidentiality clause
Party A and Party B shall undertake the confidentiality obligation for the following technical materials and data provided by them: _ _ _ _ _ _. The confidentiality period is _ _ _ _.
Article 5 Ownership of technological achievements.
During the performance of this contract, the new technological achievements completed by Party A with the technical data and working conditions provided by Party B shall be owned by Party A, and the new technological achievements completed by Party B with the technical data and working conditions provided by Party A shall be owned by Party B. (Note: the two parties may have other different agreements. )
Article 6 Party A's liability for breach of contract
1. If Party A fails to provide relevant technical data, data, samples and working conditions as agreed in the contract, which affects the quality and progress of the work, it shall pay the remuneration in full. If Party B fails to provide the agreed material and technical conditions two months overdue, Party B has the right to terminate the contract, and Party A shall pay% of the total remuneration as penalty.
2. If Party A delays the payment of remuneration, it shall pay a penalty of% of the total remuneration; If the remuneration or liquidated damages are not paid within two months, the work results shall be returned and the remuneration shall be supplemented, and the liquidated damages of _ _% of the total remuneration shall be paid.
3. If Party A fails to receive the work results, it shall pay liquidated damages of% of the total remuneration and storage fees. If Party B fails to receive the work results within two months, Party B has the right to sell and dispose of the work results. After deducting the remuneration, liquidated damages and storage fees, the rest will be returned to Party A. If the income is insufficient to pay the remuneration, liquidated damages and storage fees, Party B has the right to demand compensation from Party A..
Article 7 Party B's Liability for Breach of Contract
1. If the contract is not performed without authorization, the remuneration shall be exempted and a penalty of% of the total remuneration shall be paid.
2. If the work is not completed within the agreed time limit, the liquidated damages of the total remuneration shall be paid.
3. Those who fail to complete the work according to the quality and quantity shall be responsible for rework, improvement or full compensation. If losses are caused to Party A, it shall compensate for the losses;
4. During working hours, if it is found that the technical data, data, samples, materials or working conditions provided by the other party do not conform to the provisions of the contract, and the entrusting party is not informed within the agreed time limit, resulting in the stagnation, delay or non-performance of technical services, the remuneration shall be reduced or exempted as appropriate;
5. During the working period, if the goods provided by the entrusting party are found to be in danger of damage, and the entrusting party is not informed within the agreed time limit, it shall bear the losses caused thereby.
6. Whoever, in violation of the contract, quotes, publishes or provides relevant technical materials, data, samples or work results to a third party without authorization shall pay a penalty of _ _% of the total remuneration.
7. If the samples, data and technical data delivered by Party A are not kept properly, resulting in loss, shortage, deterioration, pollution or damage, it shall compensate for the losses.
(Note: If it is difficult to find defects in the subject matter of a technical service contract in a short time, the parties may stipulate the warranty period in the contract. If defects in service quality are found during the warranty period, the Trustee shall be responsible for rework or take remedial measures. However, due to the use of the client. Except for problems caused by improper storage. )
Article 8 Acceptance criteria and methods
1. acceptance criteria: various technical indicators agreed in this contract;
2. Acceptance method: Party A shall organize relevant professional and technical personnel in the same industry to conduct acceptance and write an acceptance report; 3. The acceptance fee shall be borne by Party A..
Article 9 Interpretation of terms and expressions: _ _ _ _ _ _ _.
Article 10 Settlement of contract disputes: _ _ _ _ _ _ _ _ _ _.
This contract shall come into effect after being signed and sealed by both parties.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Simple technical service contract mode 2
Party A:
Party B:
In order to cooperate hand in hand, promote development, satisfy interests and clarify responsibilities, Party A and Party B, based on the principle of good faith and mutual benefit, hereby sign this contract for both parties to abide by:
Article 1 Service contents, methods and requirements:
(For the technical training contract, the training contents and requirements, training plan and progress shall be filled in; Is a technical intermediary contract should fill in the intermediary content and requirements)
Article 2: Working conditions and cooperation matters:
Article 3 Time limit, place and method of performance:
Article 4: Acceptance Criteria and Methods:
Technical services or technical training shall be accepted according to standards and methods, and Party A shall issue the acceptance certificate of service or training items. The warranty period of the service items in this contract is. If defects in service quality are found during the warranty period, the Trustee shall be responsible for rework or take remedial measures. But it does not include the problems caused by improper use and storage by the entrusting party.
Article 5: Remuneration and payment methods:
1. Remuneration of this project (service fee or training fee): RMB.
The expenses required for the Trustee to complete professional technical work and solve technical problems shall be borne by the Trustee.
Two. The activity funds of the intermediary in this project are RMB, which shall be borne by the intermediary. The remuneration of the intermediary is RMB, which shall be paid by the intermediary.
Three. Payment method (as follows):
1, one-time payment: yuan, time
2. Installment payment: yuan, time
3. Other ways: yuan and times
Article 6: Calculation method of liquidated damages or damages:
In case of breach of this contract, the breaching party shall be liable for breach of contract according to the provisions of Articles 98 and 99 of the Regulations for the Implementation of the Technology Contract Law.
If the technology violates this contract, the breaching party shall bear the liability for breach of contract in accordance with the provisions of Articles 105 and 106 of the Regulations for the Implementation of the Technology Contract Law.
Where a technical intermediary breaches a contract, the breaching party shall be liable for breach of contract in accordance with the provisions of Articles 112, 113 and 114 of the Regulations for the Implementation of the Technology Contract Law.
1. In case of violation of Article of this contract, Party A shall be liable for breach of contract, with the following methods and amounts:
2. Anyone who violates the provisions of Article of this contract shall bear the liability for breach of contract. The method and amount of breach of contract are as follows:
Article 7. Solution to the dispute:
In case of any dispute during the performance of this contract, both parties shall settle it through consultation or request mediation. If both parties are unwilling to negotiate or mediate, or negotiation or mediation fails, both parties agree to adopt the following methods.
1. Any dispute arising from this contract shall be submitted to the Arbitration Commission for arbitration;
Second, solve it according to judicial procedures.
Article 8: Others (including the rights and obligations of the intermediary, service fee and payment method, deposit, property mortgage, guarantee and other matters not covered in the above clauses):
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
Simple technical service contract model 3
Customer (Party A):
Service Party (Party B):
Signature time:
In order to clarify the rights, obligations and economic responsibilities of both parties in the process of technical services, this contract is signed by both parties through consultation in accordance with the Contract Law of People's Republic of China (PRC) and relevant laws and regulations.
The first technical service content: set up a 10KV high-voltage line from Party A's substation to Jilin Xinda Foundry Co., Ltd., with a distance of about 5km.
Article 2 Technical service mode: turnkey project.
Article 3 Project execution standards: Code for Installation and Acceptance of Metallurgical Electrical Equipment Engineering (GB50397-20_) and Electrical Equipment Handover Test Standard for Electrical Installation Engineering (GB50 150-20_).
Article 4 Party A requires:
1), the line is 10KV overhead line, using cement poles, and the pole height is 12- 15m. The buried depth of cement poles shall be implemented according to the national standards, and the design shall be carried out according to the actual situation on site, which must be safe and reliable and conform to the national standards.
2) The conductor is 95mm2 polyethylene insulated steel-core aluminum stranded overhead cable, which must be a national standard cable, model: JKLGY-95/ 15.
3) Galvanized hardware, cross arm 70×8× 1400, 15KV composite silica gel insulator.
4) Introduce the 10KV/300mm2 high-voltage cable from the outgoing line of the steel plant substation into the pole, and from the pole into the incoming line of the cast substation (the cable and terminal head are provided by Party A).
5) The line has four branches, and each branch is required to install a drop switch, a lightning arrester and a grounding electrode. (a), No.2 well, (b), steel slag plant, (c), No.3, No.5 and No.6 well (d), mixing station.
6) Install 2-3 sets of lightning arresters (Y5WS- 17/50) on the line.
Article 5 Working conditions and cooperation matters provided by the entrusting party
1. The entrusting party is responsible for providing cables and cable terminal heads from the outlet of the steel plant substation to the pole and from the pole to the entrance of the casting substation.
2. Party A is responsible for coordinating the land use on the construction site.
Article 6 Time and place of contract performance
1. Conditions for dissolution of this contract: After the execution of the agreed terms in this contract, this contract will be dissolved naturally.
2. Duration: 35 days from the date of signing the contract. If the construction cannot be carried out in rainy days, the construction period will be postponed.
3. Place of performance of the contract: Hengdaohe Town, Dongfeng County, Jilin Province.
Article 7 Rights and obligations of both parties
I. Rights and obligations of the entrusting party
(1) Rights of the entrusting party
1. The entrusting party has the right to accept the results of technical service projects completed by the entrusted party;
2. The entrusting party has the right to accept the knowledge or operation technology taught by the entrusted party to solve technical problems;
3. If the entrusted party fails to complete the work results within the time limit, the entrusting party has the right to terminate the contract.
(II) Obligations of the entrusting party
1. The entrusting party shall provide the working conditions for the entrusted party and complete the work that should be coordinated according to the contract;
2. The entrusting party shall pay the technical service remuneration to the entrusted party on schedule;
3. The entrusting party shall provide the technical information to the entrusted party according to the contract.
II. Rights and obligations of service providers
(a) Rights of service providers
1. The entrusted party has the right to accept the technical data and working conditions provided by the entrusting party;
2. The Trustee shall have the right to receive remuneration for technical services after delivering the work results;
3. If the entrusting party fails to provide working conditions, the entrusted party has the right to terminate the contract.
(ii) Obligations of service providers
1. The Trustee shall complete the service content, solve the technical problems and ensure the work quality according to the contract;
2. Deliver the service results that meet the quality requirements to the entrusting party;
3. If the service results delivered by the Trustee to the Client do not meet the quality standards or are defective, they shall be reworked free of charge. If losses are caused to the entrusting party, it shall be liable for compensation.
Article 8 Acceptance criteria and methods
1. The service provider shall apply to the entrusting party for acceptance in writing after the self-inspection of the project is qualified.
Second, the implementation standards and acceptance criteria:
1, electrical equipment handover test standard for electrical installation engineering (GB50 150-20_).
2. Code for Installation and Acceptance of Metallurgical Electrical Equipment Engineering (GB50397-20_).
Third, the main control projects
1. The high-voltage insulator shall be tested in accordance with the Handover Test Standard for Electrical Equipment of Electrical Installation Engineering (GB50 150-20_).
2. The transformer neutral grounding device shall be constructed according to the low-voltage distribution system specified in the design, and the grounding resistance value of the grounding device must meet the design requirements.
Fourth, the general project
1, the depth of rod pit and wire pit shall meet the following standards:
(1) 10KV allowable error of pole pit depth -50-+ 100 mm.
(2) The verticality of the pole is 0.5D (that is, the pole is slightly inclined and displaced, and d is the pole diameter).
(3) The error between the actual sag and the design value is 5%, and the sag difference between wires in the same gear is 50.
2, cross arm, insulator and hardware installation shall meet the following requirements:
(1) The cross arm is in close contact with the pole and firmly installed, the insulator is reliably connected with the pole and wire fittings, the specifications of the fittings match the wires, and the parts are well protected against corrosion and coating.
(2) Cracks and damage defects are strictly prohibited on the surface of high-voltage porcelain insulator, and the spring pins, bolts and studs on Zhang Xuan-resistant insulator strings are installed correctly.
(3) The angle between the cross arm and the center line is correct, and the wire connection must be tight and firm. It is forbidden to have broken strands and damage at the joint, and it is forbidden to have cracks after crimping or straightening.
3, wire erection shall meet the following requirements:
(1) The conductor and insulator are fixed reliably, and the conductor is free from broken strands, twisting and dead bending.
(2) The minimum safe distance between wires, wires, wires and across the ground must be constructed according to the design specifications. After the conductor is tightened, the pole has no obvious deviation.
(3) The sharp corners of the stay poles and poles are in correct positions, with complete fittings and firm connection, and all stay wires on the same pole are uniformly stressed.
(4) The wires and stay wires, poles and frames shall be arranged reasonably and neatly, and the connection between wires shall be clear, and the net distance after installation shall not be less than 200mm.
4. The installation of electrical equipment on the pole shall meet the following requirements:
(1) The on-column switch is flexible in opening and closing operation, reliable in mechanical locking, good in three-phase synchronization of opening and closing, reliable in grounding, and the insulation resistance is not less than 0.5MΩ.
(2) The lightning arresters on the pole should be arranged neatly, with a spacing of not less than 350mm, and the conductor section should be selected correctly.
(3) The installation of lightning arrester and grounding device shall comply with the regulations.
Article 9 remuneration standards and settlement methods
I. Total contract price
Rmb: ￥1150,000 yuan (in words: one million one hundred and fifty thousand yuan only).
Second, the payment method:
1, acceptance settlement;
2. After signing the contract, Party A shall pay Party B an advance payment of 30% (three hundred and forty-five thousand yuan) of the total contract amount;
3. Party A shall pay Party B 30% of the total contract price (three hundred and forty-five thousand yuan) after all the building materials enter the factory and start construction;
4. After the project construction is completed and the power transmission is successful, Party A will pay Party B 30% (three hundred and forty-five thousand yuan) of the total contract amount after Party B issues the installation invoice of Dongfeng County Local Taxation Building with 6./kloc-0.3% of the total contract amount;
5. The remaining project payment is 65,438+00% of the total contract amount (one hundred and fifteen thousand yuan), which will be paid by Party A to Party B in one lump sum one year after the line is put into production;
Article 10 Liability for breach of contract
First, the principal's liability for breach of contract
1. If the entrusting party fails to provide relevant technical information, data and working conditions, which affects the progress and quality of the work and causes economic losses to the entrusted party, the entrusting party shall compensate the entrusted party according to the losses.
2. If the principal fails to pay the remuneration or the remuneration is insufficient, the agent has the right to require the principal to pay within a time limit.
Second, the service party's liability for breach of contract
1. If the Consignee fails to perform the technical service contract or delays the delivery of service results, thus causing economic losses to the Consignor, the Consignee shall compensate the Consignor according to the actual economic losses.
2. If the service results delivered by the Consignee are defective and cause economic losses to the Consignor, the Consignee shall bear the losses.
3. If the Consignee causes the loss or damage of the technical data delivered by the Entrusting Party, the Consignee shall be responsible for compensating the losses.
Article 11 Ways to settle disputes
If there is any dispute in the execution of the contract, both parties shall settle it through consultation in time. If negotiation fails, either party may apply to the economic contract arbitration commission with jurisdiction for arbitration, or directly bring a lawsuit to the people's court with jurisdiction.
Article 12 Supplementary Provisions
Matters not covered in this contract shall be governed by People's Republic of China (PRC) Contract Law.
Party A (official seal): _ _ _ _ Party B (official seal): _ _ _ _ _
Legal representative (signature): _ _ _ _ _ Legal representative (signature): _ _ _ _ _
_ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
3 Simple technical service contract mode related articles:
★ Three selected concise technical service contract templates.
★ Simple technical service contract template 3 latest article
★ 3 latest simple technical service contracts
★ 3 simple technical consulting service contract templates
★ Simple technical service contract template
★ Collect 3 model technical service contracts.
★ Simple version of technical service contract template
★ 20 19 3 demonstration technical service contract
★ 3 standard templates for technical service contracts
★ 3 Simple technical consulting service contract model article is the latest.